Justia U.S. Federal Circuit Court of Appeals Opinion Summaries

PDIC’s patent allegedly covers encoding digital images in the JPEG format. PDIC licensed the patent to Adobe, promising not to sue Adobe or Adobe’s customers for claims arising “in whole or part owing to an Adobe Licensed Product.” PDIC sued Adobe customers, alleging that encoding JPEG images on the customers’ websites infringed its patent. Adobe was allowed to intervene to defend nine customers, asserting that PDIC breached its license agreement. PDIC dismissed the actions in which Adobe had intervened. Adobe unsuccessfully sought "exceptional case" attorneys’ fees, 35 U.S.C. 285, and FRCP 11 sanctions. The court concluded that it could not determine the prevailing party nor "say that PDIC’s pre-suit investigation was inadequate or that any filing was made for any improper purpose.” The court denied in part PDIC’s motion for summary judgment, finding that a reasonable juror could find "that PDIC’s infringement allegations . . . cover the use of Adobe products,” and violated the agreement; it held that Adobe could only collect fees incurred in defending its customers in suits that violated the agreement but could not recover fees incurred in the affirmative breach-of-contract suit. After failed attempts to identify "purely defense fees,” Adobe requested judgment in favor of PDIC. The court reiterated “that there are purely defensive damages that can be proven,” but entered the judgment. The Federal Circuit dismissed an appeal for lack of jurisdiction. There was no final ruling barring recovery on Adobe’s breach claim. Under New Jersey law, actual damages are not a required element of a breach of contract claim. View "Princeton Digital Image Corp. v. Office Depot Inc." on Justia Law

During World War II, the Hanford Nuclear Reservation was established by the U.S. Army Corps of Engineers. After the war, Hanford continued in use, operated by contractors. Each time the work was transferred to another contractor, the employees that performed the work would stay the same, typically with the same pay and benefits. The Hanford Multi-Employer Pension Plan (MEPP) was established in 1987 as a contract between “Employers,” defined as named contractors, and “Employees.” The government is not a party to the MEPP but may not be amended without government approval. In 1996, some employees accepted employment with a Hanford subcontractor, Lockheed, and were informed that, upon their retirement, they would not receive retirement benefits that were previously afforded under the MEPP. They were subsequently told that they would remain in the MEPP but that, instead of calculating their pension benefits based on their total years in service, their benefits would be calculated using the highest five-year salary, and that they could not challenge the change until they retired. This became a MEPP amendment. In 2016, former Lockheed employees sued the government, alleging that an implied contract was breached when they did not receive benefits based on their total years in service. The Federal Circuit held that the former employees did not prove that an implied-in-fact contract existed. The government funds Lockheed and others to manage Hanford, but there is no evidence that the government intended to be contractually obligated to their employees; there was no mutuality of intent. View "Turping v. United States" on Justia Law

K-Con and the Army entered into two contracts for pre-engineered metal buildings. K-Con claims that the Army subsequently delayed issuance of a notice to proceed for two years, resulting in $116,336.56 in increases in costs and labor. According to K-Con, this delay was due solely to the government’s decision to add to each contract the performance and payment bonds set forth in Federal Acquisition Regulation (FAR) 52.228-15. The Armed Services Board of Contract Appeals held that bonding requirements were included in the contracts by operation of law when they were awarded, pursuant to the Christian doctrine. The Federal Circuit affirmed. The two contracts are construction contracts and, under the Christian doctrine, the standard bond requirements in construction contracts were incorporated into K-Con’s contracts by operation of law. If the contracts had been issued using the standard construction contract form, there would have been no issue, but these contracts issued using the standard commercial items contract form. There were, however, many indications that the contracts were for construction, not commercial items. The statement of work included many construction-related tasks, including developing and submitting construction plans, obtaining construction permits, and cleaning up construction areas. The statement of work also required compliance with FAR regulations relevant only to construction contracts. View "K-Con, Inc. v. Secretary of the Army" on Justia Law

The VA and Department of Defense (DoD) committed to developing an integrated electronic health records (EHR) system to replace their separate systems but abandoned that plan. DoD replaced its system with a commercially-available system, consisting primarily of software developed by Cerner. The VA issued a request for information and engaged a consultant, Thornton, to assess four options—three involving an off-the-shelf EHR system, and the fourth involving modernizing its existing system. Thornton concluded that the market could support all four options and that the VA’s best option for improving interoperability with the DoD would depend on the VA’s own evaluation. The VA chose to acquire a new system and invoked the public-interest exception to the Competition in Contracting Act’s open competition requirement, 41 U.S.C. 3301, 3304(a)(7), to negotiate a sole-source contract with Cerner “for the acquisition of the [EHR] system being deployed by the [DoD] and related services.” CliniComp, an incumbent provider of EHR systems to the VA, filed a bid protest, asserting that the sole-source decision lacked a rational basis and violated the Act. The Claims Court dismissed. The Federal Circuit affirmed. CliniComp lacked standing to protest the decision. To establish standing, CliniComp had to show that it was “an actual or prospective bidder” and had a “direct economic interest in the procurement or proposed procurement.” CliniComp did not establish that it had the kind of experience that would enable it to compete for the work contemplated by the VA’s planned contract. View "CliniComp International, Inc. v. United States" on Justia Law

Scotty, born in 1979 at Madigan Army Medical Center, suffered injuries during childbirth, resulting in brain damage, cerebral palsy, seizures, and blindness, necessitating ongoing, around-the-clock care. The Shaws sued and agreed to a settlement, which stated that payments described in paragraph 5 and the purchase of annuities described in paragraph 6 “shall constitute a complete release.” Paragraph 5 provided that the government would pay: $500,000 to the Shaws; $500,000 to Scotty's medical trust; $850,000 to the Shaws’ attorneys; and, for the purchase of annuities to provide payments set forth in paragraph 6, $2,950,000.00. Paragraph 6 set forth the terms for the annuities. Four annuities are at issue: one each for Mr. and Ms. Shaw, one for the guardianship for the benefit of Scotty, and one for the medical trust. The government made each of the specified payments, including $2,846,095 to purchase the annuities. The agreement stated that payments from the annuities for Mr. and Ms. Shaw “are guaranteed for a period of twenty (20) years.” Paragraph 7 noted that the “settlement is contingent on a total, final cost of $4,800,000.00.” The annuities were purchased from ELNY, which later encountered financial difficulties and entered into court-ordered liquidation in 2012. The Shaws's annuity payments were reduced by 20%; payments to the guardianship and the medical trust were reduced by 62.4%. The Shaws sued. The Federal Circuit affirmed summary judgment in favor of the government, which was obligated to guarantee the annuity payments only for the first 20 years. The reduction in payments began after that period. The Shaws lacked standing to sue on behalf of the medical trust. View "Shaw v. United States" on Justia Law

Plaintiffs each entered into agreements to provide services to Voice of America (VOA), a U.S. government-funded broadcast service. The agreements were a series of individual purchase order vendor (POV) contracts that each plaintiff entered into over several years with the Broadcasting Board of Governors (BBG), which oversees VOA. In 2014, the Office of Inspector General for the U.S. Department of State issued a report that was critical of the BBG’s use of POV contracts, concluding that the BBG was using such contracts in some cases to obtain personal services. Plaintiffs filed a class action complaint alleging that, along with other individuals who have served as independent contractors for VOA, they should have been retained through personal services contracts or appointed to positions in the civil service. If their contracts had been classified as personal services contracts or they had been appointed to civil service positions, they alleged, they would have enjoyed enhanced compensation and benefits. The Claims Court dismissed and denied their request for leave to file a proposed second amended complaint. The Federal Circuit affirmed, rejecting several contract-based claims, seeking damages for the loss of the additional compensation and benefits to which Plaintiffs contend they were entitled. Plaintiffs have set forth no viable theory of recovery. View "Lee v. United States" on Justia Law

XY’s patents relate to the sorting of X- and Y-chromosome-bearing sperm cells, for selective breeding purposes. Trans Ova provides services related to embryo transfer and in-vitro fertilization for cattle. XY and Trans Ova entered into a five-year licensing agreement in 2004 under which Trans Ova was authorized to use XY’s technology, subject to automatic renewal unless Trans Ova was in material breach. In 2007, Inguran acquired XY and sent a letter purporting to terminate the Agreement because of alleged breaches. For several years, the parties negotiated but failed to resolve their disputes. Trans Ova continued to make royalty payments to XY, which were declined. XY alleges that it became aware of further breaches, including underpayment of royalties and development of improvements to XY’s technology without disclosure of such improvements to XY. XY sued for patent infringement and breach of contract. Trans Ova counterclaimed, alleging patent invalidity, breach of contract, and antitrust violations. The district court granted XY summary judgment on the antitrust counterclaims. A jury found breaches of contract by both parties; that Trans Ova failed to prove that the asserted patent claims were invalid and willfully infringed the asserted claims; and XY was entitled to patent infringement damages. The court denied all of Trans Ova’s requested relief and granted XY an ongoing royalty. The Federal Circuit affirmed except the ongoing royalty rate, which it remanded for recalculation. View "XY, LLC v. Trans Ova Genetics, L.C." on Justia Law

TAOS and Intersil were both developing ambient light sensors for electronic devices. Ambient light sensors use a silicon- or other semiconductor-based photodiode that absorbs light and conducts a current. The resulting photocurrent is detected by a sensor, and measurements of the current, a function of the ambient light, are used to adjust the brightness of an electronic screen display. One benefit is better visibility; another is improved battery efficiency. In 2004, the parties confidentially shared technical and financial information during negotiations regarding a possible merger that did not occur. Soon after, Intersil released new sensors with the technical design TAOS had disclosed in the confidential negotiations. TAOS sued for infringement of its patent, and for trade secret misappropriation, breach of contract, and tortious interference with prospective business relations under Texas state law. A jury returned a verdict for TAOS and awarded damages on all four claims. The Federal Circuit affirmed liability for trade secret misappropriation, though on a more limited basis than TAOS presented to the jury, and affirmed liability for infringement of the asserted apparatus claims of the patent, but vacated the monetary awards. The court noted that there was no evidence of Intersil’s independent design of the photodiode array structure. View "Texas Advanced Optoelectronic Solutions, Inc. v. Renesas Electronics America, Inc." on Justia Law

In 2003, the Coalition Provisional Authority (CPA) was established to rule Iraq pending transfer of authority to the Iraqi Interim Government (IIG). CPA awarded Agility a Contract to operate warehouses, providing that “[t]he obligation under this contract is made with Iraqi funds.” Agility acknowledged the impending transfer of authority and CPA’s scheduled dissolution. CPA authorized the IIG Minister of Finance to delegate contract administration to CPA’s Program Management Office (PMO). CPA administered Development Fund for Iraq (DFI), composed of various sources, including revenue from sales of Iraqi petroleum and natural gas. The IIG Minister delegated contract-administration responsibility concerning DFI-funded contracts to the PMO but did not give PMO contracting authority. Subsequent Contract task orders obligated U.S. funds. A U.S. contracting officer (CO) determined that Agility owed the government $81 million due to overpayment. Separately, Agility unsuccessfully sought $47 million for unpaid fees. The Armed Services Board of Contract Appeals dismissed Agility's appeals for lack of jurisdiction under the Contract Disputes Act (CDA), 41 U.S.C. 7101–7109. The Federal Circuit affirmed. The Board’s CDA jurisdiction is limited to contracts “made by an ‘executive agency.’” CPA was not an executive agency under the CDA. CPA awarded the Contract and there was no evidence that it was novated or assigned to an executive agency. The government acted as a contract administrator, not as a contracting party. View "Agility Logistics Services Co., KSC v. Mattis" on Justia Law

Meridian contracted to construct the Chula Vista Project flood control project, including construction of concrete channels, relocation of a sewer line, and dewatering and water diversion. After commencing work, Meridian encountered problems relating to “a layer of dripping saturated dark clay material under which a clean layer of sand is producing water” with “the potential for serious structural damage.” The government issued contract modifications, including an increase in funds for larger pipe, addition of a reinforced concrete access ramp, investigation of soil properties, remediation of saturated soils, and additional sheet piling. The government directed Meridian to suspend work following structural failures and terminated the project following a final inspection. Meridian sued for breach of contract, breach of the duty of good faith and fair dealing, and violation of the Contract Disputes Act, 41 U.S.C. 601−613. The government conceded liability for certain costs relating to suspension of work, channel fill, and interim protection. With respect to other claims, the Federal Circuit affirmed in part. Meridian’s interpretation of the contract was not reasonable; the existence of subsurface saturated soil conditions was “reasonably foreseeable.” The Trade Court did not impose an improper requirement for investigation of site conditions beyond what a reasonable contractor would undertake. The court remanded for consideration of whether the parties reached a meeting of the minds on flood event claims and held that the Trade Court erred dismissing Meridian’s unpaid contract quantities claim, in light of conflicting information. View "Meridian Engineering Co. v. United States" on Justia Law